Serving Royal Palm Beach, FL and surrounding areas. (561) 359-1679
Effective Date: January 1, 2026
By using the website at royalpalmbeachsunrooms.com or by engaging Royal Palm Beach Lanai Sunrooms & Patios ("Company," "we," "us," or "our") for any service, you agree to be bound by these Terms and Conditions. If you do not agree, please do not use our website or services.
These Terms apply to all visitors to our website and to all customers who engage us for sunroom, patio enclosure, or related construction services.
Royal Palm Beach Lanai Sunrooms & Patios is a sunroom and patio enclosure contractor based in Royal Palm Beach, Florida. We offer sunroom additions, four season sunrooms, three season sunrooms, patio enclosures, screen room installation, custom sunrooms, patio conversions, and related residential construction services in Palm Beach County and surrounding areas.
All services are subject to a signed written contract between the customer and Royal Palm Beach Lanai Sunrooms & Patios. No work will begin without a signed contract and the required deposit on file.
Written estimates provided by Royal Palm Beach Lanai Sunrooms & Patios are based on the information available at the time of the site visit. Estimates are valid for 30 days from the date of issue. Final pricing is confirmed in the written contract signed by both parties before work begins.
Estimates are not binding quotes. Final project cost may vary if unforeseen site conditions are discovered during construction - for example, existing structural issues, utility conflicts, or soil conditions that require additional work. We will notify you in writing of any change order before performing additional work.
Permit fees, HOA submission fees, and costs imposed by Palm Beach County or any homeowners association are the responsibility of the customer and will be itemized separately in the contract.
Construction start dates are scheduled after permits and any required HOA approvals are in hand. We will provide you with an estimated start date once all required approvals are received. Start dates may shift due to permit processing delays, weather conditions, or material lead times.
If you need to cancel or postpone a scheduled project, please notify us in writing as soon as possible. Cancellation terms - including any applicable fees or deposit forfeitures - are set out in your individual contract. Weather-related delays do not constitute a cancellation by either party.
Payment terms are set out in your signed project contract. Typically, a deposit is required before work begins, with additional payments due at defined project milestones, and a final payment due upon project completion.
Final payment is due upon completion of the project and passing of any required county inspections. Invoices not paid within the time period stated in your contract may be subject to late fees as specified therein.Royal Palm Beach Lanai Sunrooms & Patios reserves the right to suspend work on projects where milestone payments are not received on schedule.
Royal Palm Beach Lanai Sunrooms & Patios will apply for required building permits with Palm Beach County on behalf of the customer. The customer is responsible for obtaining any required HOA approvals before permit application. We will assist in preparing HOA submission documents upon request, but the customer must submit and follow up with their HOA directly.
No construction will begin prior to receipt of all required permits and approvals. Delays caused by permit processing or HOA review do not constitute a breach of contract by Royal Palm Beach Lanai Sunrooms & Patios.
Royal Palm Beach Lanai Sunrooms & Patios warrants its workmanship for a period of one year from the date of final project completion. This warranty covers defects in materials and labor performed by our crew. It does not cover damage caused by severe weather events, misuse, modifications made by others, or normal wear and tear.
Manufacturer warranties on products such as windows, glass panels, and roofing materials are passed through to the customer and are subject to each manufacturer's terms and conditions.
The website at royalpalmbeachsunrooms.com and all information on it is provided "as is" without any warranty of accuracy, completeness, or fitness for a particular purpose.
To the maximum extent permitted by applicable law, Royal Palm Beach Lanai Sunrooms & Patios shall not be liable for any indirect, incidental, consequential, or punitive damages arising from the use of our website or from any project we perform, even if we have been advised of the possibility of such damages.
Our total liability for any claim arising from a project shall not exceed the total amount paid by the customer for that specific project. Nothing in these Terms limits our liability for personal injury caused by our negligence or for fraud.
If a dispute arises between you and Royal Palm Beach Lanai Sunrooms & Patios, we ask that you contact us first at info@royalpalmbeachsunrooms.com so we can try to resolve it directly.
If direct resolution is not possible, any dispute, claim, or controversy arising out of or relating to these Terms or our services shall be resolved by binding arbitration administered in Palm Beach County, Florida, in accordance with applicable arbitration rules. Each party is responsible for their own legal costs unless the arbitrator rules otherwise.
These Terms and Conditions are governed by and construed in accordance with the laws of the State of Florida, without regard to its conflict of law provisions. Any legal proceedings not subject to arbitration shall be brought in a court of competent jurisdiction in Palm Beach County, Florida.
Royal Palm Beach Lanai Sunrooms & Patios reserves the right to update these Terms and Conditions at any time. Changes will be posted on this page with a revised effective date. Continued use of our website or services after any changes constitutes your acceptance of the updated Terms.
Questions about these Terms and Conditions? Reach us at:
Royal Palm Beach Lanai Sunrooms & Patios
146 Heatherwood Dr
Royal Palm Beach, FL 33411
